NOTICE TO CREDITORS

Docket: PR035396

In Re the Matter of: Sidney Chism Jr.

Notice is hereby given that on the 9th day of Apr., 2026, Letters of Administration in respect of Sidney Chism Jr., who died Dec. 18, 2025, were issued to the undersigned by the Probate Court of Shelby County, Tennessee.

All persons, resident and non-resident, having claims, matured or unmatured, against the estate are required to file the same with the Clerk of the above named Court on or before the earlier of the dates prescribed in (1) or (2), otherwise their claims will be forever barred.

(1)(A) Four (4) months from the date of the first publication (or posting, as the case may be) of this notice if the creditor received an actual copy of this Notice to Creditors at least sixty (60) days before the date that is four (4) months from the date of the first publication (or posting); or

(B) Sixty (60) days from the date the creditor received an actual copy of the Notice to Creditors, if the creditor received the copy of the notice less than sixty (60) days prior to the date that is four (4) months from the date of first publication (or posting) as described in (1)(A); or

(2) Twelve (12) months from the decedent’s date of death.

This 9th day of Apr., 2026.

Lyrial Marie Chism Administrator(s)

Attorney for the Estate:

Tricia M.Y. Tweel

Mary Kathryn Brogan

Apr. 15, 22, 2026 Cd113890

NOTICE TO CREDITORS

Docket: PR035436

In Re the Matter of: Ronda Sue Campbell

Notice is hereby given that on the 13th day of Apr., 2026, Letters Testamentary in respect of Ronda Sue Campbell, who died Mar. 3, 2026, were issued to the undersigned by the Probate Court of Shelby County, Tennessee.

All persons, resident and non-resident, having claims, matured or unmatured, against the estate are required to file the same with the Clerk of the above named Court on or before the earlier of the dates prescribed in (1) or (2), otherwise their claims will be forever barred.

(1)(A) Four (4) months from the date of the first publication (or posting, as the case may be) of this notice if the creditor received an actual copy of this Notice to Creditors at least sixty (60) days before the date that is four (4) months from the date of the first publication (or posting); or

(B) Sixty (60) days from the date the creditor received an actual copy of the Notice to Creditors, if the creditor received the copy of the notice less than sixty (60) days prior to the date that is four (4) months from the date of first publication (or posting) as described in (1)(A); or

(2) Twelve (12) months from the decedent’s date of death.

This 13th day of Apr., 2026.

Margaret Mary Caffrey Executor

Attorney for the Estate:

Tricia M.Y. Tweel

Mary Kathryn Brogan

Apr. 15, 22, 2026 Cd113888

NOTICE TO CREDITORS

Docket: PR034829

In Re the Matter of: Myrna A. Whitt

Notice is hereby given that on the 9th day of Apr., 2026, Letters Testamentary in respect of Myrna A. Whitt, who died Dec. 18, 2025, were issued to the undersigned by the Probate Court of Shelby County, Tennessee.

All persons, resident and non-resident, having claims, matured or unmatured, against the estate are required to file the same with the Clerk of the above named Court on or before the earlier of the dates prescribed in (1) or (2), otherwise their claims will be forever barred.

(1)(A) Four (4) months from the date of the first publication (or posting, as the case may be) of this notice if the creditor received an actual copy of this Notice to Creditors at least sixty (60) days before the date that is four (4) months from the date of the first publication (or posting); or

(B) Sixty (60) days from the date the creditor received an actual copy of the Notice to Creditors, if the creditor received the copy of the notice less than sixty (60) days prior to the date that is four (4) months from the date of first publication (or posting) as described in (1)(A); or

(2) Twelve (12) months from the decedent’s date of death.

This 9th day of Apr., 2026.

Lydia W. Rosencrants Executor

Attorney for the Estate:

Lindsay A. Jones

Kala C. David

Audrey L. Davis

Emily Claire Horobetz

Apr. 15, 22, 2026 Cd113856

NOTICE TO CREDITORS

Docket: PR035177

In Re the Matter of: Philip Micahel Deming

Notice is hereby given that on the 9th day of Apr., 2026, Letters of Administration in respect of Philip Micahel Deming, who died Dec. 11, 2025, were issued to the undersigned by the Probate Court of Shelby County, Tennessee.

All persons, resident and non-resident, having claims, matured or unmatured, against the estate are required to file the same with the Clerk of the above named Court on or before the earlier of the dates prescribed in (1) or (2), otherwise their claims will be forever barred.

(1)(A) Four (4) months from the date of the first publication (or posting, as the case may be) of this notice if the creditor received an actual copy of this Notice to Creditors at least sixty (60) days before the date that is four (4) months from the date of the first publication (or posting); or

(B) Sixty (60) days from the date the creditor received an actual copy of the Notice to Creditors, if the creditor received the copy of the notice less than sixty (60) days prior to the date that is four (4) months from the date of first publication (or posting) as described in (1)(A); or

(2) Twelve (12) months from the decedent’s date of death.

This 9th day of Apr., 2026.

James Deming Administrator(s)

Attorney for the Estate:

Bruce Douglas Brooke

Dustin E. Lepkowicz

Apr. 15, 22, 2026 Cd113854

ORDER OF PUBLICATION

In the CHANCERY COURT of Shelby County, Tennessee

No. CH-26-0139

PADGETT LAW GROUP as trustee for

NATIONSTAR MORTGAGE, LLC D/B/A MR. COOPER

Plaintiff(s)

VS.

THE ESTATE AND UNKNOWN HEIRS OF DOUGLAS H. WILLIAMS, TONIA WILLIAMS, KEONDRA WILLIAMS, TAYLOR MELLETT, CARLEIGH GRACE MELLETT, SAMANTHA MELLETT, JAMIE HALL A/K/A JAMIE MELLETT A/K/A JAMIE L. JACKSON AND THE ESTATE AND UNKNOWN HEIRS OF THOMAS FREY MELLETT JR.

Defendant(s)

It appearing from the complaint in this cause which is sworn to that

1.   The names and whereabouts of the estate, unknown heirs and next of kin of Douglas H. Williams cannot be ascertained upon diligent inquiry; and

2. Service by publication is therefore appropriate pursuant to Tennessee Rules of Civil Procedure.

It is therefore ordered that unknown heirs make defense appearance herein at the Court House of Shelby County, in the city of Memphis, Shelby County, TN on June 5, 2026, and answer plaintiffs' complaint for lnterpleader on Sworn account or the same will be taken for confessed as to defendant(s), and set for hearing ex parte, and that a copy of this order be published once a week for four successive weeks in the Daily News and Daily Memphian

This 10 day of April, 2026.

A True Copy - Attest:

W. Aaron Hall, Clerk & Master

By Sam Ginsberg, D.C. & M.

Zachary B. Johnson

Attorney for Petitioners

Apr. 15, 22, 29, May 6, 2026 Cd113845

IN THE JUVENILE COURT OF MEMPHIS AND SHELBY COUNTY, TENNESSEE

No. EE0438

State of Tennessee

Department Of Children Services,

IN THE MATTER OF:

Tradarion McNary, DOB: 05/24/2012

A Child under Eighteen (18) Years of Age

ORDER OF PUBLICATION

Magistrate Yetunde Aird’s Court Order dated March 23, 2026 is incorporated in part, as follows:

In this cause, it appearing to the court from the allegations of the petition filed, and the sworn testimony of the Department that the residence of respondent Nicole Taylor is unknown and cannot be ascertained by diligent search and inquiry; and that the whereabouts of Respondent Nicole Taylor Cannot be found or the post office address of Respondent Nicole Taylor cannot be ascertained, and therefore, the ordinary process of law cannot be served upon Respondent Nicole Taylor.

IT IS THEREFORE ORDERED that the Motion for Order of Publication shall be granted.

Clerk’s Notice to Respondent:

The Department, has filed a Petition against you seeking Dependency and Neglect. It appears that ordinary process of law cannot be served upon you because your whereabouts are unknown. In order to avoid a judgement by Default against you, you must appear in Court or file an answer to the Petition filed against you. The date being the 26th of June, 2026 at 9:00 A.M. All future hearings/or documents filed in this cause shall be filed with the Clerk and shall be considered as service upon you. You may request all pleadings filed in this cause from the Clerk of Court. Service of notice of these proceedings shall occur for four (4) consecutive weeks in the Daily News of Memphis, Tennessee, and for four weeks on the online news website for The Daily Memphian, as your whereabouts are unknown.

JANEEN R. GORDON, CLERK OF COURT

BY Ann Jones

Submitted by and approved for entry.

Alexandra Tallent, BPR 032203

Department of Children’s Services

40 South Main Street, 6th Floor

Memphis, TN 38103

901-578-4161

Apr. 1, 8, 15, 22, 2026 Cd113612

Order of Publication

Case ID: CT-2035-24

Kierra Shante Moses

vs.

Christopher Jerome Polk

It appearing from the petition filed in this case that the residence of defendant, Christopher Jerome Polk is unknown and cannot be ascertained upon diligent search and inquiry.

IT IS THEREFORE ORDERED that the defendant appear in Circuit Court in the Shelby County Courthouse, Memphis, Tennessee within 30 days of the last date of this publication, and, plead, answer or demur to complainant's bill for divorce, or the same will be taken for confessed as to the defendant and this cause proceeded with ex parte, and that a copy of this order be published once a week for four consecutive weeks in the Daily News and the Daily Memphian.

This 27th day of March, 2026.

Jamita Swearengen,

Circuit Court Clerk

Natasha Pugues, Deputy Clerk

Nicole M. Grida

Attorney for Complainant

Apr. 1, 8, 15, 22, 2026 Cd113605

ORDER OF PUBLICATION

In the CHANCERY COURT of Shelby County, Tennessee

No. CH-25-1816

Marcus Davis

Plaintiff(s)

VS.

Mary Gavrock Colucci Basham, and the Unknown Heirs of Mary Gavrock Colucci Basham

Defendant(s)

It appearing from the complaint in this cause which is sworn to that the whereabouts of the defendants, Mary Gavrock Colucci Basham, and the Unknown Heirs of Mary Gavrock Colucci Basham, have been unable to be ascertained.

It is therefore ordered that they make their appearance herein at the Court House of Shelby County, in the city of Memphis, Shelby County, TN on May 22, 2026 and answer plaintiffs' complaint for Quiet Title or the same will be taken for confessed as to defendant(s), and set for hearing ex parte, and that a copy of this order be published once a week for four successive weeks in the Daily News and online at the Daily Memphian.

This 27th day of March, 2026.

A True Copy- Attest:

W. Aaron Hall, Clerk & Master

By Kamilah Mull, D.C. & M.

Alex Alpert

Attorney for Petitioners

Apr. 1, 8, 15, 22, 2026 Cd113577

ADVERTISEMENT FOR BIDS

PROJECT #1

TAD No. 79-555-0131-25

BCA-000-7918

Millington Airport Authority, Tennessee

Project #2

TAD No. 79-555-0134-25

BCA-000-4132

Millington Airport Authority, Tennessee

Separate sealed BIDS for the construction of Project #1 – REHABILITATE SOUTH APRON will be received by the Millington Airport Authority, Tennessee, hereinafter referred to as the OWNER, at the Airport Conference Room until 2:00 P.M., local time, THURSDAY, MAY 14, 2026. BIDS will then be publicly opened and read aloud. Bids received after this time will not be accepted and will be returned unopened.

The Work includes the following principal items: Milling, paving, and marking operations.

A Pre-Bid Conference will be held at 2:00 P.M. local time, THURSDAY, APRIL 30, 2026, at the Millington Airport Authority, 8182 Hornet Avenue, Millington, Tennessee 38053. Due to the importance of all bidders having a clear understanding of the scope and requirements for this contract, it is strongly encouraged that bidders attend this meeting. Any changes that may be agreed upon as a result of this meeting will be noted in an addendum sent to all plan holders.

Total Contract Time for completion of the work is sixty (60) calendar days.

Liquidated damages for delay will be in the amount of $2,500.00 per calendar day that the project remains incomplete after the specified completion time.

Separate sealed BIDS for the construction of Project #2 – EAST SIDE REVITALIZATION OF TAXILANE AND VEHICULAR ACCESS ROAD will be received by the Millington Airport Authority, Tennessee, hereinafter referred to as the OWNER, at the Airport Conference Room until 2:30 P.M., local time, THURSDAY, MAY 14, 2026. BIDS will then be publicly opened and read aloud. Bids received after this time will not be accepted and will be returned unopened.

The Work includes the following principal items: Milling, paving, and marking operations.

A Pre-Bid Conference will be held at 2:00 P.M. local time, THURSDAY, APRIL 30, 2026, at the Millington Airport Authority, 8182 Hornet Avenue, Millington, Tennessee 38053. Due to the importance of all bidders having a clear understanding of the scope and requirements for this contract, it is strongly encouraged that bidders attend this meeting. Any changes that may be agreed upon as a result of this meeting will be noted in an addendum sent to all plan holders.

Total Contract Time for completion of the work is sixty (60) calendar days.

Liquidated damages for delay will be in the amount of $2,500.00 per calendar day that the project remains incomplete after the specified completion time.

Other Bidding Requirements, Contract Forms, Conditions of the Contract, Specifications, Drawings and other Bidding and Contract Documents may be examined at the office of the following:

 Barge Design Solutions, Inc., 65 Germantown Court, Suite 100, Memphis, Tennessee 38018;

 (901) 755-7166

 Millington Airport Authority, Tennessee, 8182 Hornet Avenue, Millington, Tennessee 38053;

 (901) 872-7495

Electronic and printed copies of bidding Documents may be obtained from https://bidding.bargedesign.com/. For questions about ordering documents, call the Barge Plan Room c/o Memphis Reprographics at 901-381-9811. Call prior to picking up documents to ensure availability. Partial sets of Bidding Documents will not be available directly from the Issuing Office. Neither Owner nor Engineer will be responsible for full or partial sets of bidding Documents including Addenda, if any, obtained from sources other than the Issuing Office. No part of the purchase will be refunded.

Bid Security: A certified check or bank draft drawn on a solvent bank, payable without condition to the OWNER, or a bid bond of an amount not less than (5%) of the base bid amount shall be submitted with each bid as a guarantee that, if the bid is accepted, a contract will be entered into, and the performance of the contract properly secured.

Contract Security: The Successful BIDDER will be required to furnish separate performance and payment bonds payable to the OWNER. Each bond shall be in an amount equal to 100% of the Contract Price as security for CONTRACTOR'S faithful performance and payment of all obligations under the Contract Documents.

No BID may be withdrawn by the BIDDER within one hundred and twenty (120) days after actual date of opening thereof.

BIDS in the case of corporations not chartered in Tennessee, must be accompanied by proper certificate evidencing that such corporation is authorized to do business in the State of Tennessee.

Bids are to be based upon prevailing wages in Shelby County, Tennessee; and in no case are wages considered less than those predetermined by the Secretary of Labor, a schedule of which is contained in the Contract Documents.

The Successful BIDDER whether a resident or nonresident shall be required to comply with all City, County and State licensing and/or permit laws.

Any contract(s) awarded pursuant to this ADVERTISEMENT FOR BIDS may be funded in part by a grant from the U.S. Department of Transportation, Federal Aviation Administration. Neither the United States nor any of its departments, agencies or employees is or will be a party to this ADVERTISEMENT FOR BIDS or any resulting contract. This procurement will be subject to regulations contained in Airport and Airway Department Act of 1982, as amended. Bidders must comply with the following:

(a) The Buy American Preference incorporates statutory requirements and policies outlined in 49 U.S.C. § 50101, Executive Order 14005, and Build America, Buy America Act (BABA);

(b) Title VI of the Civil Rights Act of 1964 (Public Law 88-352);

(c) Davis Bacon Act (40 USC 3141-3144, 3146, & 3147) as supplemented by Department of Labor Regulations (29 CFR Part 5, 2 CFR Part 200, Appendix II(D), and 49 USC 47112(b));

(d) Federal Debarment and Suspension laws in accordance with 2 CFR Part 180 (Subpart B), 2 CFR Part 200, Appendix II(H), 2 CFR Part 1200, DOT Order 4200.5, and Executive Orders 12549 and 12689;

(e) Federal laws regulating Lobbying and Influencing Federal Employees in accordance with 31 USC § 1352 – Byrd Anti-Lobbying Amendment, 2 CFR Part 200, Appendix II(I), and 49 CFR Part 20, Appendix A;

(f) Section 6002 of the Solid Waste Disposal Act, as amended by the Resource Conservation and Recovery Act, and the regulatory provisions of 40 CFR Part 247.

Title VI Solicitation Notice:

The Millington Airport Authority, in accordance with the provisions of Title VI of the Civil Rights Act of 1964 (78 Stat. 252, 42 U.S.C. §§ 2000d to 2000d-4), 28 CFR § 50.3, and 49 CFR Part 21, hereby notifies all bidders that it will affirmatively ensure that any contract entered into pursuant to this advertisement, all contractors will be afforded full opportunity to submit bids in response to this invitation and will not be discriminated against on the grounds of the owner’s race, color, national origin, sex, creed, age, or disability in consideration for an award.

DBE Solicitation Notice (No DBE Contract Goal):

The requirements of 49 CFR Part 26 including any amendments thereto apply to this contract. It is the policy of the Millington Airport Authority to practice nondiscrimination based on race, color, sex, or national origin in the award or performance of this contract. The Owner encourages participation by all firms qualifying under this solicitation regardless of business size or ownership.

Federal Fair Labor Standards Act Notice:

All contracts and subcontracts that result from this solicitation incorporate by reference the provisions of 29 CFR Part 201, et seq, the Federal Fair Labor Standards Act (FLSA), with the same force and effect as if given in full text. The FLSA sets minimum wage, overtime pay, recordkeeping, and child labor standards for full and part-time workers.

The Contractor has full responsibility to monitor compliance to the referenced statute or regulation. The Contractor must address any claims or disputes that arise from this requirement directly with the U.S. Department of Labor – Wage and Hour Division.

Trade Restriction Certification

By submission of an offer, the Offeror certifies that with respect to this solicitation and any resultant contract, the Offeror –

a)       is not owned or controlled by one or more citizens of a foreign country included in the list of countries that discriminate against U.S. firms as published by the Office of the United States Trade Representative (USTR);

b)       has not knowingly entered into any contract or subcontract for this project with a person that is a citizen or national of a foreign country included on the list of countries that discriminate against U.S. firms as published by the USTR; and

c)        has not entered into any subcontract for any product to be used on the Federal project that is produced in a foreign country included on the list of countries that discriminate against U.S. firms published by the USTR.

Prohibition of Covered Unmanned Aircraft Systems (UAS)

The Bidder or Offeror certifies that they are aware of and comply with relevant Federal statutes and regulations, including those from the Federal Aviation Administration (FAA), for operating unmanned aircraft systems (UAS) in accordance, and in compliance with all related requirements in the FAA Reauthorization Act of 2024 (Public Law 118-63), section 936 (49 U.S.C. § 44801 note).

Contractor warrants that all UAS operations will be conducted in full compliance with all applicable Federal Aviation Administration (FAA) regulations, including but not limited to 14 CFR Part 107, and any other applicable local, state, or Federal laws and regulations. 

Sponsors and subgrant recipients cannot use AIP grant funds to enter into, extend, or renew a contract related to covered unmanned aircraft systems (UAS). This includes both procurement and operational contracts, as well as contracts with entities that operate such systems.

The Owner reserves the right to refuse to issue a proposal form to a prospective bidder should such bidder be in default for any of the following reasons:

(a) Failure to comply with any prequalification regulations of the Owner, if such regulations are cited, or otherwise included, in the proposal as a requirement for bidding.

(b) Failure to pay, or satisfactorily settle, all bills due for labor and materials on former contracts in force (with the owner) at the time the owner issues the proposal to a prospective bidder.

(c) Contractor default under previous contracts with the Owner.

(d) Unsatisfactory work on previous contracts with the Owner.

BIDS for Project #1 shall be on the forms included in the Bidding Documents and submitted in an opaque sealed envelope. Bid envelope must contain on the outside of the envelope, the Contractor’s current Certificate of Responsibility Number and the Contractor’s License Number unless a statement on the exterior says that the bid enclosed is less than or did not exceed $50,000.00. Bid envelope shall also be clearly identified on the outside as follows:

BID FOR CONSTRUCTION OF REHABILITATE SOUTH APRON

PROJECT #1

TAD NO. 79-555-0131-25

BCA-000-4132

SUBMITTED BY: (Name of Bidder with Bidder's Current Tennessee Contractor's License Number).

The BID shall be addressed to:

Mike Gill

AIRPORT DIRECTOR

8182 Hornet Avenue

Millington, Tennessee 38053

BIDS submitted by mail shall be registered.

BIDS for Project #2 shall be on the forms included in the Bidding Documents and submitted in an opaque sealed envelope. Bid envelope must contain on the outside of the envelope, the Contractor’s current Certificate of Responsibility Number and the Contractor’s License Number unless a statement on the exterior says that the bid enclosed is less than or did not exceed $50,000.00. Bid envelope shall also be clearly identified on the outside as follows:

BID FOR CONSTRUCTION OF EAST SIDE REVITALIZATION OF TAXILANE AND VEHICULAR ACCESS ROAD

PROJECT #2

TAD NO. 79-555-0134-25

BCA-000-4132

SUBMITTED BY: (Name of Bidder with Bidder's Current Tennessee Contractor's License Number).

The BID shall be addressed to:

Mike Gill

AIRPORT DIRECTOR

8182 Hornet Avenue

Millington, Tennessee 38053

BIDS submitted by mail shall be registered.

The OWNER reserves the right to reject any and all BIDS, to waive any informalities or irregularities in the BIDS received, and to accept the BID which is deemed most favorable to the OWNER at the time and under the conditions stipulated.

END OF ADVERTISEMENT FOR BIDS

Apr. 15, 2026 Bd113891

LEGAL NOTICE TO BIDDERS

Sealed bids (or Request for Proposals, where indicated as RFP) will be received at the Office of the City of Memphis Purchasing Agent, Room 368, City Hall, 125 N. Main St., Memphis, TN  38103, until 12:00 noon Wednesday, on the dates indicated below, for furnishing the City of Memphis with the following:

PRODUCTS AND/OR SERVICES

DUE APRIL 29, 2026

(1) RFQ #354776

 ASPHALT PLANT MAINTENANCE FOR PUBLIC WORKS DIVISION

(2) RFQ #354777

 GRASS CUTTING SERVICES FOR PUBLIC WORKS DIVISION

(3) RFQ #354778

 FORKLIFT PARTS & LABOR

(4) RFQ #354780

 ASPHALT CUT AND PATCH REPAIR

(5) RFQ #354781

 PARTS WASHING MACHINES, SOLVENTS AND SERVICE FOR GENERAL SERVICES FLEET DIVISION

(6) RFQ #354782

 MOPAR AUTOMOBILE REPAIR, PARTS, & LABOR FOR PUBLIC WORKS DIVISION

By Order of the Mayor of the City of Memphis, Tennessee.

 Paul A. Young

 Mayor

Chequita Crim, City of Memphis Sourcing & Purchasing Agent

Apr. 14, 15, 2026 Bd113871

MEMPHIS LIGHT, GAS AND WATER DIVISION

CITY OF MEMPHIS

MEMPHIS, TENNESSEE

CONTRACT NAME: NORTH SERVICE CENTER BUILDING 2

ROOF REPLACEMENT

CONTRACT NO: 12622

NOTICE TO BIDDERS

All Sealed Bids, Bidder’s Qualifications, and completed Bid Envelopes, in duplicate, will be received from bidders on Tuesday, May 12, 2026, at the Contracts Management Office, Memphis Light, Gas and Water Division (“MLGW” or “Division”), Room 323, 220 South Main Street, Memphis, Tennessee 38103 (mailing address: P.O. Box 430, Memphis, TN 38101- 0430), prior to 4:00 PM CDT/CST. If you bring your bid to MLGW, please allow 30 minutes prior to 4:00 PM CDT/CST for MLGW security clearance and delivery of bids to the Contracts Management Department. The official time of receipt will be established in the Contracts Management Department and not at the main floor security desk. Bids will be publicly opened and read on Wednesday, May 13, 2026, at 2:00 PM CDT/CST.

The project scope is to remove and demolish the existing roof and install a new roofing system at MLGW’s North Service Center, Building 2 located at 1060 Tupelo St., Memphis, TN 38108. The selected Contractor shall include in their Total Lump Sum Cost all labor, material, equipment, and insurance to complete the work as depicted in strict accordance as outlined in the Contract Documents, Specifications, and Drawings.

Mandatory Site Visit and Location:

Tuesday, April 21, 2026 ~ 9:00 AM CST

MLGW’s North Service Center, Building 2

1060 Tupelo St.

Memphis, TN 38108

Written Inquiries:

Questions about this Sealed Bid must be submitted to MLGW in writing via email to scollins@mlgw.org with “Contract No. 12622– Written Inquiry” in the subject line by no later than 2:00 PM CST on Friday, April 24, 2026.

All Bidders must be licensed contractors as required by Title 62, Chapter 6, of the Tennessee Code Annotated. The following information must be completed on the outside of the preprinted Bidder’s Envelope: Bidder's Name, Bidder’s license number, expiration date, and that part of the classification applying to the bid (e.g., electrical, plumbing, heating, ventilation, and air conditioning). If the preceding information is not completed, the bid shall not be opened or considered by MLGW.

The Tennessee Contractor’s Classification required for this project shall be one of the following or any Tennessee-approved contractor’s license applicable to this project: BC or BC-21.

If a State of Tennessee Contractor’s license is required the Contractor’s license monetary limits must meet or exceed the Contractor’s bid price.

Bidder Qualifications:

Qualifications (pages BB–14 through BB–16) are due on or before Monday, April 27, 2026,

by Noon CST via email to Shelby Collins, scollins@mlgw.org, only.

The Bidder’s Qualifications must be submitted by reference letter as listed in the Bidder’s Qualifications. The Bidder’s Qualifications must indicate Contract Number 12622 – North Service Center Building 2 Roof Replacement on the front page of the Bidder’s Qualifications.

MLGW shall give Local Bidding Preference or Local Bidding Presence in the awarding of contracts and making purchases whenever applying such a preference is reasonable in light of the dollar- value of the bids received in relation to such expenditures. For Local Bidding Preference or Local Bidding Presence to be used in evaluating bids, all documentation as required in the Local Bidding Preference or Local Bidding Presence Policy must be submitted with the Bidder’s qualifications.

MLGW is subject to the Tennessee Public Records Act. Your bid may be examined by the public after it has been evaluated by MLGW and an award has been made.

This project is exempt from the mandatory contractor’s licensing requirements if the bid amount is under

$25,000.

If the bid amount is under $25,000, the phrase “Exempt from licensing requirement” must appear in the Tennessee License number space on the preprinted bid envelope provided. However, other required information (e.g., Project title, contractor’s company name, contractor’s address and bid due date) must be completed.

Bidders interested in participating in the MLGW bid solicitation process should read the Standards of Business Conduct found at www.mlgw.com/sbc.

All Sealed Bids, Bid Bonds, and a completed Bid Envelope must be received by the Contracts Management Office by no later than 4:00 PM CDT/CST on Tuesday, May 12, 2026, via hand-delivered or mailed to MLGW’s Administration Building, 220 South Main Street, Memphis, TN 38103. Bids received after the bid due date will not be accepted.

*Electronic submissions will not be accepted. Only hard copies of the bid documents will be accepted.*

Bids will be publicly opened and read via Zoom on Wednesday, April 8, 2026, at 2:00 PM CDT/CST.

?                     https://us06web.zoom.us/j/87289730125?pwd=HhrFMV1rtfuIpQmhydk8LgESQkJkqy.1

?                     Meeting ID: 872 8973 0125

?                     Passcode: 339348

A packet of the Contract Documents may be obtained by contacting the Contracts Management

Office, 220 South Main Street, Room 323, Memphis, Tennessee.

If, after attempting to obtain competitive bids for material or services, only one (1) bid is received and that bid does not exactly meet our specifications or budgetary limits, the Procurement and Contracts Management staff shall have the authority to negotiate with the Bidder to secure an acceptable bid.

Any protest must be filed in writing with the Manager of Procurement and Contracts by 5:00 PM CDT/CST within five (5) business days of the Notification of the Intent to Award Letter or non-award incident. A protest may be submitted electronically on company letterhead to the Manager of Procurement and Contracts, Randy Orsby, by 5:00 PM CST/CDT at rorsby@mlgw.org. For a copy of the MLGW Procurement Complaints and Appeals Process, visit www.mlgw.com/protest or call (901) 528-4381.

Before the execution of this Contract, the successful Bidder shall be required to furnish a Performance Bond in an amount equal to 100% of the bid price or such lesser amount as determined at the sole discretion of MLGW. The bond shall be made upon the form in this packet and shall be made a part of the Contract. The Surety Company shall be acceptable to MLGW.

Before the execution of the contract, the successful Bidder shall furnish, according to the Tennessee Code Annotated § 12-4-201, a Contractor’s Labor and Materials Payment Bond in a determined sum of no less than 25% of the bid price. The bond shall be made upon the form provided by MLGW in this packet and shall be made part of the Contract Documents. Such a surety shall be acceptable to MLGW.

All contract bonds shall be written through a surety company duly authorized to do business in

Tennessee.

No bidder may withdraw a bid for a period of 120 days after the date and hour set for the opening

of bids.

MLGW reserves the right to reject bids, to waive Minor Irregularities in the bids received, and to accept any bid or portion of the bid, which MLGW, in MLGW’s sole discretion, deems most favorable to the interest of MLGW.

Direct all questions to Shelby Collins at scollins@mlgw.org; (901) 528-4020.

MEMPHIS LIGHT, GAS, AND WATER DIVISION

Tausha Kelly

Supervisor, Contracts Management

P. O. Box 430, Memphis, Tennessee 38101-0430

220 South Main Street, Memphis, TN 38103-3917

Apr. 14, 15, 2026 Bd113842

LEGAL NOTICE TO BIDDERS

SHELTERED MARKET BID (RFQ) OPPORTUNITY

Sealed bids or proposals will be received by Memphis Light, Gas and Water Division (MLGW) via its iSupplier Portal prior to 4:00 PM CDT/CST Tuesday, April 21, 2026, for furnishing 4,599 – TAP KITS, RFQ # 1801950.

CONTACT: LUCY VICK-WATSON

TITLE: PROCUREMENT CONTRACTS SPECIALIST I

purchasing@mlgw.org

(901) 528-4701

Apr. 10, 14, 15, 2026 Bd113802

MEMPHIS LIGHT, GAS AND WATER DIVISION

CITY OF MEMPHIS

MEMPHIS, TENNESSEE

SUBSTATION RELAY ASSISTANCE

CONTRACT NO: 12628

NOTICE TO BIDDERS

All Sealed Bids, Bid Bonds, Bidder’s Qualifications, and completed Bid Envelope will be received from Bidders on Tuesday, May 12, 2026, at the Contracts Management Office, Memphis Light, Gas and Water Division (“MLGW” or “Division”), Room 323, 220 South Main Street, Memphis, Tennessee 38103 (mailing address: P.O. Box 430, Memphis, TN 38101-0430), before 4:00 PM CDT/CST. If you bring your bid to MLGW, please allow 30 minutes before 4:00 PM CDT/CST for MLGW security clearance and delivery of bids to the Contracts Management Department. The official time of receipt will be established in the Contracts Management Department and not at the main floor security desk. *Bids will be publicly opened and read on Wednesday, May 13, 2026, at 2:00 PM CDT/CST.

The project scope is to furnish all supervision, labor, equipment, tools, supplies, transportation of equipment/labor, transportation of materials supplied by the Contractor and/or materials supplied by MLGW, to construct, program, troubleshoot, and maintain MLGW’s Distribution Automation Equipment to current Construction Standards. This work will be performed in the secondary power space on MLGW’s overhead electric distribution system (12kV and 23kV as directed by the designated MLGW Representative throughout Memphis and Shelby County, TN. The work must be performed in accordance with the requirements of the MLGW Relay Department Foreman or Engineer and in strict accordance with the Contract Documents and Specifications.

Written Inquiries:

Questions regarding this Sealed Bid must be submitted to MLGW in writing via email to jpayne@mlgw.org with “Contract No. 12628 – Written Inquiry” in the subject line by no later than 10 AM CST on Wednesday, April 22, 2026.

All Sealed Bids, Bid Bonds, and completed Bid Envelopes must be received by the Contracts Management Office no later than 4:00 PM CDT/CST on Tuesday, May 12, 2026, via hand-delivered or mailed to MLGW’s Administration Building, 220 South Main Street, Memphis, TN 38103. Bids received after the bid due date will not be accepted.

*Electronic submissions will not be accepted. Only hard copies of the bid documents will be accepted. *

Bids will be publicly opened and read via Zoom on Wednesday, May 13, 2026, at 2:00 PM CDT/CST.

?          https://us06web.zoom.us/j/87289730125?pwd=HhrFMV1rtfuIpQmhydk8LgESQkJkqy.1

?          Meeting ID: 872 8973 0125

?          Passcode: 339348

Apr. 15, May 5, 2026 Bd113736

MEMPHIS LIGHT, GAS AND WATER DIVISION

CITY OF MEMPHIS

MEMPHIS, TENNESSEE

SHEAHAN PUMPING STATION SITE WORK (COAL CHUTE REPAIRS)

CONTRACT NO: C2881

NOTICE TO BIDDERS

All Sealed Bids, Bid Bonds, Bidder’s Qualifications, and completed Bid Envelopes must be received from Bidders on Tuesday, May 5, 2026, at the Management Office, Memphis Light, Gas and Water Division (“MLGW” or “Division”), Room 323, 220 South Main Street, Memphis, Tennessee 38103 (mailing address: P.O. Box 430, Memphis, TN 38101-0430), prior to 4:00 PM CDT/CST. If you bring your bid to MLGW, please allow 30 minutes prior to 4:00 PM CDT/CST for MLGW security clearance and delivery of bids to the Contracts Management Department. The official time of receipt will be established in the Contracts Management Department and not at the main floor security desk. *Bids will be publicly opened and read on Wednesday, May 6, 2026, at 2:00 PM CDT/CST.

The scope of the work is to perform demolition and replacement of concrete slab over the existing coal chute tunnel, including the removal of the existing steel rails and replacement of the concrete slab between the existing support beams at MLGW Sheahan Pumping Station located at 3941 Grandview Avenue, Memphis, TN 38111 as outlined in the Contract Document and Specifications.

Mandatory Site Visit and Location:

MLGW Sheahan Pumping Station ~ Tuesday, April 14, 2026 ~ 9:00 AM CST 3941 Grandview Avenue

Memphis, TN 381111

*Potential Bidders are required to attend the Mandatory Site Visit. Failure to attend will deem your firm unqualified to bid on this project.

*All Bidders must complete the Bidding Blank in its entirety, please put “N/A” for items that do not apply to the Bidder.

Written Inquiries:

Questions regarding this Sealed Bid must be submitted to MLGW in writing via email to acotton@mlgw.org with “Contract No. C2881 – Written Inquiry” in the subject line by no later than 11:00 AM CST on Monday, April 20, 2026.

During the solicitation of this Sealed Bid, the Bidders shall not contact any MLGW staff except those designated in this document or subsequent addenda or correspondence. Noncompliance with this provision may result in the rejection of your firm’s bid. No phone calls related to this Sealed Bid will be accepted.

All Bidders must be licensed contractors as required by Title 62, Chapter 6, of the Tennessee Code Annotated. The following information must be completed on the outside of the preprinted Bidder’s Envelope: Bidder’s Name, Bidder’s license number, expiration date, and that part of the classification applying to the bid (e.g., electrical, plumbing, heating, ventilation, and air conditioning). If the preceding information is not completed, the bid shall not be opened or considered by MLGW.

The Tennessee Contractor’s Classification required for this project shall be one of the following or any Tennessee-approved contractor’s license applicable to this project: BC

If a state of Tennessee Contractor’s license is required, the Contractor’s license monetary limits must meet or exceed the Contractor’s bid price.

MLGW shall give Local Bidding Preference or Local Bidding Presence in the awarding of contracts and making purchases whenever applying such a preference is reasonable in light of the dollar value of the bids received in relation to such expenditures. For Local Bidding Preference or Local Bidding Presence to be used in evaluating bids, all documentation as required in the Local Bidding Preference or Local Bidding Presence Policy must be submitted with the Bidder’s qualifications.

MLGW is subject to the Tennessee Public Records Act. Your bid may be examined by the public after it has been evaluated by MLGW and an award has been made.

This project is exempt from the mandatory contractor’s licensing requirements if the bid amount is under $25,000.

If the bid amount is under $25,000, the phrase “Exempt from licensing requirement” must appear in the Tennessee License number space on the preprinted bid envelope provided. However, other required information (e.g., Project title, contractor’s company name, contractor’s address, and bid due date) must be completed.

Bidders interested in participating in the MLGW bid solicitation process should read the Standards of Business Conduct found at www.mlgw.com/sbc.

All Sealed Bids, Bid Bonds, Bidder’s Qualifications, and completed Bid Envelopes must be received by the Contracts Management Office by no later than 4:00 PM CDT/CST on Tuesday, May 5, 2026, via hand delivery or mailed to MLGW’s Administration Building, 220 South Main Street, Memphis, TN 38103. Bids received after the bid due date will not be accepted.

*Electronic submissions will not be accepted. Only hard copies of the bid documents will be accepted. *

Bids will be publicly opened and read via Zoom on Wednesday, May 6, 2026, at 2:00 PM CDT/CST.

?                        https://us06web.zoom.us/j/87289730125?pwd=HhrFMV1rtfuIpQmhydk8LgESQkJkqy.1

?                        Meeting ID: 872 8973 0125

?                        Passcode: 339348

The Bidder’s Qualifications must be submitted by reference letter as listed in the Bidder’s Qualifications. The Bidder’s Qualifications must indicate Contract Number C2881 and title on the front page of Bidder’s Qualifications and so noted on the outside of the envelope.

A packet of the Contract Documents may be obtained by contacting the Contracts Management Office, 220 South Main Street, Room 323, Memphis, Tennessee 38103.

If after attempting to obtain competitive bids for material or services, only one (1) bid is received and that bid does not exactly meet our specifications or budgetary limits, the Procurement and Contracts Management staff shall have the authority to negotiate with the bidder to secure an acceptable bid.

Any protest must be filed in writing with the Manager of Procurement and Contracts by 5:00 PM CST/CDT within five (5) business days of the Notification of the Intent to Award Letter or non-award incident. Protest may be submitted electronically on company letterhead to the Manager of Procurement and Contracts, Randy Orsby, by 5:00 PM CST/CDT at rorsby@mlgw.org. For a copy of the MLGW Procurement Complaints and Appeals Process visit www.mlgw.com/protest or call (901) 528-4020.

Before the execution of this Contract, the successful bidder shall be required to furnish a Performance Bond in an amount equal to 100% of the bid price or such lesser amount as determined at the sole discretion of MLGW. The bond shall be made upon the form in this packet and shall be made a part of the Contract. The surety company shall be acceptable to MLGW.

Before the execution of the contract, the successful Bidder shall furnish, pursuant to Tennessee Code Annotated § 12-4-201, a Contractor’s Labor and Materials Payment Bond in a determined sum of no less than 25% of the bid price. The bond shall be made upon the form provided by MLGW in this packet and shall be made part of the Contract Documents. Such surety shall be acceptable to MLGW.

All contract bonds shall be written through a surety company duly authorized to do business in Tennessee. No bidder may withdraw a bid for 120 days after the date and hour set for the opening of bids.

MLGW reserves the right to reject bids, to waive Minor Irregularities in the bids received, and to accept any bid or portion of the bid, that MLGW, in MLGW’s sole discretion, deems most favorable to the interest of MLGW.

Direct all questions to Aline Cotton at acotton@mlgw.org; (901) 528-4020.

MEMPHIS LIGHT, GAS AND WATER DIVISION

Tausha Kelly

Supervisor, Contracts Management

P. O. Box 430, Memphis, TN 38101-0430

220 South Main Street, Memphis, TN 38103-3917

Apr. 3, 8, 15, 21, 2026 Bd113671

PUBLIC NOTICE

Pursuant to Section 42, Article IV of the Code of Shelby County, a Special Meeting of the Groundwater Quality Control Board for Shelby County to discuss the Groundwater Protection Plan will be held on May 7, 2026, 10:00 A.M. – 12:00 P.M. The meeting will be held at the Shelby County Health Department EHS building at 1826 Sycamore View Rd, Memphis, TN 38134 – Conference room #2.

You may express your desire to make public comment (or comment) by submitting an email to waterpubliccomment@shelbyCountytn.gov or by requesting a public comment card at the meeting. Questions concerning the meeting may be addressed to Operations Manager, Mrs. Sonja Owens at 901-222-9598 or Mrs. Warkella Tyson-Winston by calling 901-222-9572 or via email at Warkella.winston@shelbyCountytn.gov.

Apr. 15, 2026 Md113899

NOTICE

The following vehicles will be sold on 4/25/2026 at Auction by SAT Towing and Recovery LLC at 4300 New Getwell Rd, Memphis, TN 38118.

The owner has the right to make prior claim at the sale date at the address listed above.

Year Make Model VIN

2012 CHRYSLER 200 1C3CCBBB1CN188618

2014 HONDA ACCORD 1HGCR2F52EA274501

2008 NISSAN TITAN 1N6BA07D88N351667

2010 NISSAN ALTIMA 1N4AL2AP3AN431090

2004 HONDA ACCORD 1HGGCM56644A060262

2011 HYUNDAI GENESIS KMHGC4DE7BU137091

2007 TOYOTA CAMRY 4T1BE46K07U044105

2007 CHEVROLET SILVERADO 2GCEC13CX71717030

2009 DODGE CARAVAN 1D8HN44EX9B507444

2009 CHEVROLET MALIBU 1G1ZH57B29F182405

2013 VOLKSWAGEN TIGUAN WVGAV7AX4DW545952

2012 MAZDA CX9 JM3TB2CA7C0350146

2016 CHEVROLET EQUINOX 2GNALBEK1G6173777

2005 HONDA ACCORD 1HGCM56725A165148

2015 CHEVROLET CRUZ 1G1PC5SB8F7284357

Apr. 15, 2026 Md113897

NOTICE OF SALE OF REAL PROPERTY

BY SHELBY COUNTY GOVERNMENT

Notice is hereby given that Shelby County Government has received an Offer to Purchase for the following property:

Christopher Munn

Tax Parcel # 04801100000350

Price Offered: $1,575.00

Offers to Purchase must be submitted within Ten (10) working days of this notice.

All properties sold AS-IS, WHERE IS without warranties of any sort.

SHELBY COUNTY LAND BANK

1075 MULLINS STATION BLDG. E-1, MEMPHIS, TN 38134

LandBank.ShelbyCountyTN.gov

Apr. 15, 2026 Md113894

NOTICE OF SALE OF REAL PROPERTY

BY SHELBY COUNTY GOVERNMENT

Notice is hereby given that Shelby County Government has received an Offer to Purchase for the following property:

LaAunzae Grady

Tax Parcel # 04301000000290

Price Offered: $1,275.00

Offers to Purchase must be submitted within Ten (10) working days of this notice.

All properties sold AS-IS, WHERE IS without warranties of any sort.

SHELBY COUNTY LAND BANK

1075 MULLINS STATION BLDG. E-1, MEMPHIS, TN 38134

LandBank.ShelbyCountyTN.gov

Apr. 15, 2026 Md113892

NOTICE

I am seeking clear title on a 2009 Nissan Rogue VIN #JN8AS58T19W040502.

Anyone claiming interest please contact Jeanette Scott at 2948 Montague Cv., 38114 (314) 915-3540 within 10 days of this notice.

Apr. 15, 2026 Md113881

NOTICE OF SALE OF REAL PROPERTY

BY SHELBY COUNTY GOVERNMENT

Notice is hereby given that Shelby County Government has received an Offer to Purchase for the following property:

Marcela Macha & Susan Vicinanza

Tax Parcel # 02607300000160

Price Offered: $300.00

Offers to Purchase must be submitted within Ten (10) working days of this notice.

All properties sold AS-IS, WHERE IS without warranties of any sort.

SHELBY COUNTY LAND BANK

1075 MULLINS STATION BLDG. E-1, MEMPHIS, TN 38134

LandBank.ShelbyCountyTN.gov

Apr. 15, 2026 Md113879

NOTICE OF SALE OF REAL PROPERTY

BY SHELBY COUNTY GOVERNMENT

Notice is hereby given that Shelby County Government has received an Offer to Purchase for the following property:

Nicholus Bowers

Tax Parcel #03904700000140 Price Offered: $800.00

Tax Parcel #03904700000150 Price Offered: $200.00

Offers to Purchase must be submitted within Ten (10) working days of this notice.

All properties sold AS-IS, WHERE IS without warranties of any sort.

SHELBY COUNTY LAND BANK

1075 MULLINS STATION BLDG. E-1, MEMPHIS, TN 38134

LandBank.ShelbyCountyTN.gov

Apr. 15, 2026 Md113866